Commercial Monthly Maintance
Michael Strasser
239-821-2048 FLORIDA    770-406-0453 GEORGIA
sclassical89@aol.com
CLASSICAL ENTERPRISE                                                                                                            DATE: _________ 2009
2978 Buford Hwy Suite120-119  Cummings, Ga 30041                                                                         PAGE:  #__ OF __   
770-871-1389         Web Site: WWW.MICHAELJSTRASSER.COM  E-MAIL- SCLASSICAL89@AOL.COM

THIS SERVICE AGREEMENT made by and between ________________________________________ hereinafter called Client, and CLASSICAL ENTERPRISE . Hereinafter called Company.
Service Address: ________________________________________________________________________
City: ____________________________________  State: Georgia              Zip: _______________
Billing Address:_____________________________________________Contact Name:________________________________
City: __________________________________________________ State: Georgia Zip: _________________________
Phone: ____-____-________Corp Phone:__________________ Fax: __________________ E-Mail:______________________

SERVICE INFORMATION   ( NUMBER OF LOCATIONS _____ )
Type of Property:                            Type of Service:                                    Service Schedule: 
___ Residential                                ___ Pressure Cleaning          ___ Monthly ___ Quarterly ___ Semi-Yearly ___ One Time
___ Commercial                              ___ Building Maintenance   ___ As Needed ___ Not Included
___ Rental Property                        ___ Line Striping                  ___ Maintenance: ___ Semi-Annual  ___ N/A
                                                       ___ Seal Coating                 ___ Maintenance: ___ Semi-Annual  ___ N/A     
 
CLIENT AND COMPANY agree, The Company, its agents and its assigns are hereby retained by the client to provide the selected services, at the service address or addresses listed above and attached documents, all in accordance with the terms and conditions set forth herein.


TERMS


WORK TO BE COMPLETED:
1. _____________________________________________________________________________________________
2. _____________________________________________________________________________________________
3. _____________________________________________________________________________________________
4._____________________________________________________________________________________________    
5._____________________________________________________________________________________________
6._____________________________________________________________________________________________
7._____________________________________________________________________________________________
8_____________________________________________________________________________________________
9._____________________________________________________________________________________________
MATERIALS:
1. _____________________________________________________________________________________________
2._____________________________________________________________________________________________
3._____________________________________________________________________________________________
4._____________________________________________________________________________________________
5._____________________________________________________________________________________________
RATES INCLUDING MATERIALS, LABOR AND DISPOSAL OF MATERIALS
Total Rate:  $___________
ALL RATES SUBJECT TO CHANGE DUE TO UNFORESEEN PROBLEMS
PAYMENT SCHEDULE: $ ____ ___    Due Upon Booking
                                   $ ______    _ Due START OF WORK
                                   $ _______     Due __________________
                                   $ _______     Upon Completion

Proposed Start Date: ______________2011   Proposed Completion Date: _______________2011

ALL DATES SUBJECT TO CHANGE DUE TO WEATHER OR UNFORESEEN PROBLEMS 
ALL RATES SUBJECT TO CHANGE DUE TO UNFORESEEN PROBLEMS. ALL DATES SUBJECT TO CHANGE DUE TO WEATHER OR UNFORESEEN PROBLEMS. NOT RESPONSIBLE FOR DAMAGE DUE TO ROTTED WOOD, IMPROPER INSULATION OF EXISTING STRUCTURES OR NEGLECT. ADDITIONAL COSTS MAY ARISE FROM HIDDEN PROBLEMS BEHIND WALLS OR ENCLOSED IN EXISTING STRUCTURE. THESE COSTS AND ANY ADDITIONAL WORK REQUESTED OR DEEMED NECESSARY, AT THE SOUL DESECRATION OF THE CONTRACTOR, FOR THE PROPER INSTALLATION OF THE CONTRACTED WORK SHALL BE PAID IN FULL BEFORE ANY OTHER WORK PROCEEDS. CLIENT IS RESPONSIBLE FOR All PERMITS, AND ANY FINES, DELAY OF WORK, ADDITIONAL WORK OR LEGAL COSTS IF PERMITS ARE NOT PULLED IN THE PROPER AND TIMELY MANNER. ALL NEW AGREEMENTS NULL AND VOID ALL PREVIOUS AGREEMENTS WRITTEN OR VERBAL. THERE WILL BE A 20% CANCELLATION FEE OF THE TOTAL RATE AND A 25% RESTOCKING FEE OF MATERIALS IF APPLICABLE.. A DELAY OF WORK FEE OF $300.00 PER DAY APPLIES TO ANY DELAYS ARISING FROM AND NOT LIMITED TO THE CHANGING OF CONTRACT WITH DELAY AS PER PERMITS, REFUSAL OF WORK DEEMED NECESSARY FOR PROPER INSTALLATION AND COLOR CHANGE AFTER CLIENT APPROVAL. CLIENT IS RESPONSIBLE TO MAKE SURE THAT THE WORK AREA IS FREE OF ALL PESTS AND HAZARDOUS CONDITIONS. COMPLETION IS DEFINED BY THE SOUL DISCRETION OF COMPANY
PLEASE READ THIS AGREEMENT THOROUGHLY BEFORE SIGNING. Client acknowledges receipt of a signed copy of this Agreement.

CLIENT:
CLASSICAL ENTERPRISE
Click to authorize work to be completed
Signature: The Sending  of this document acknowledges
Authorized Representative:the under-named Representative has
authorization to enter into the terms of this agreement

Printed Name:                                                   Printed Name:  Michael J Strasser

This agreement is not binding on the Company until signed by an authorized manager or executive officer of the Company.
RIGHT TO CANCEL: You, the buyer, may cancel this transaction at any time to midnight of the third business date after the date of this transaction. You may cancel by sending written notice to CLASSICAL ENTERPRISE At the above address.




1. SERVICE. The Company will provide labor and materials to the property located at the Addresses to perform the services in accordance with the terms and conditions of this Agreement. This Agreement does not include any additional work and maintenance; any additional work will be billed on a case-by-case situation. Client acknowledges that the Company reserves the right to terminate service if Client’s account with the Company is more then thirty (30) days in arrears. The Company’s acceptance of any payment in arrears will not constitute a waiver of the Company’s right to terminate service .Client agrees to hire company as an employee for any and all work company may not be licensed to perform.

2. TERM. The parties agree that the initial term of this Agreement will be twelve (12) months and that this Agreement will be automatically renewed for an additional twelve (12) months periods following the expiration of the initial term or any renewal term. The Company reserves the right to increase the price of service upon written notice to Client at least thirty (30) days prior to such increase taking effect. This Agreement may be terminated by the Company or Client upon written notice to the other party ay least thirty (30) days prior to the next scheduled service.

3. PAYMENT. Unless Client prepays annually. The Company will invoice Client on a monthly basis for the services to be performed in that month. The full amount indicated on the invoice will be due and payable on the 1st day of every regular service month. Invoices that are not paid within thirty (30) days of the invoice date will accrue interest on the unpaid balance at a rate equal to the lesser of 1.5% per month (18% per year) or the maximum amount allowed by law. In the event that legal action is necessary to collect any amount due the Company, the Company will be entitled to recover from Client all costs of collection, including reasonable attorney’s fees, in addition to all outstanding amounts due the Company.

4. ACCESS TO PROPERTY. Client hereby grants the Company service technicians access to the property for the purpose of performing periodic service as described herein.

5. DISCLAIMERS AND LIMITATION OF LIABILITY.  The Company will not be responsible for any past, present, or future damage to the property serviced under this Agreement or the contents located at such property caused by rotted wood, improper insulation of existing structures or neglect. All rates  are subject to change due to unforeseen circumstances. All dates are subject to change due to weather or unforeseen circumstances. Additional costs may arise from hidden problems behind walls or enclosed in the existing structure. These costs and any additional work requested or deemed necessary, at the soul desecration of the Company, for the proper performance of herein services or completion of contracted work will be paid in full before any other work or services are performed. Client is responsible for any and all permits, and any fines, delay of work, additional work or legal costs if permits are not pulled in a proper and timely manner. A delay of work fee of $300.00 per day applies to any delays arising from and not limited to the changing of Agreements with delays as per permits, refusal to authorize work deemed necessary for the proper installation or completion of services and any color change after Client’s approval. Client is responsible to insure that work area is free of pests and hazardous conditions. Completion is defined by the soul discretion of the Company.

6.  ARBITRATION. Client  and Company agree that any controversy or claim between them arising out of or relating to this Agreement will be settled exclusively by arbitration, except that the Company reserves the right to sue Client in a court of law for any amount due the Company from Client. Such arbitration will be conducted in accordance with the commercial arbitration rules, then in force, of the American Arbitration Association. The arbitration award will be final and binding on both parties. Judgment upon such arbitration award may be entered in any court of competent jurisdiction. The arbitrator will not have the power or authority to award exemplary, treble, liquidated or punitive damages.

7. RIGHT TO SELL, ASSIGN OR TRANSFER. Company reserves the right to sell, transfer or assign this agreement.

8. ENTIRE AGREEMENT AND SEVERABILITY. This Agreement constitutes the entire agreement between the parties. Client expressly warrants and represents that, in entering this Agreement, Client is not relying on any promise, agreement or statement, weather oral or written, that is not expressly and fully set forth in this Agreement. If any part of this Agreement is held to be invalid or unenforceable for any reason, the remaining terms and conditions of this Agreement will remain in full force and effect.